HomeMy WebLinkAboutCity Council Resolution 2473.5 RESOLUTION NO. 2473.5
RESOLUTION OF THE CITY COUNCIL OF THE CITY OF SARATOGA
CALLING FOR CONSTRUCTION BIDS
VILLAGE PARKING DISTRICT NO. 3
The City Council of the City of Saratoga resolves:
1. This Council has given preliminary approval to the
report of the Engineer of Work for improvements in Village Parking
District No. 3, City of Saratoga, Santa Clara County, California.
The report includes plans and specifications for the construction of
improvements described in the report.
2. The City of Saratoga will receive sealed proposals for
this construction not later than 11:00 A.M. on July 27, 1988, in the
office of the City Clerk located at 13777 Fruitvale Avenue,
Saratoga, California 95070. At that time and place the sealed
proposals will be publicly opened, examined and declared.
3. The City Council reserves the power in its discretion
to reject all proposals. The award of construction contract, if
made, shall be made to the lowest responsible bidder within the time
fixed in the specifications (or any extension of time agreed to by
the City and the lowest responsible bidder).
4. The City Clerk is directed to publish a notice inviting
sealed proposals in the SARATOGA NEWS in accordance with the
Municipal Improvement Act of 1913. -The Engineer of Work is
authorized to give additional notice and to distribute additional
information as necessary in the judgment of the Engineer of Work, to
secure competitive bidding.
5. The City Council hereby determines that in the event
the contractor does not complete the work within the time specified
in the proposed contract or within such further time as this Council
shall have authorized, the contractor shall pay to the City
liquidated damages in the amount of $200.00 per day for each and
every calendar day's delay in finishing the work beyond the
completion date specified in said contract. Additional provisions
with regard to said time of completion and liquidated damages are
set forth in the specifications, which provisions are hereby
referred to and incorporated herein by reference.
, , ,
The above and foregoing resolution was passed and adopted
at a regular adjourned meeting of the Saratoga City Council held on
the 30th day of June, 1988, by the following vote:
AYES: Co~cilmenters Cleanget, ~a~, ~yles aM ~yor Peterson
NOES: ~ne
ABSENT: ~
~mc ilmember ~
Mayor
ATTEST:
Deb~YCi~erk
2